Terms & Conditions

1.     Definitions

1.1   “Supplier” means NPE-Tech Limited its successors and assigns or any person acting on behalf of and with the authority of NPE-Tech Limited.

1.2   “Customer” means the person/s buying the Goods as specified in any invoice, document or order, and if there is more than one Customer is a reference to each Customer jointly and severally.

1.3   “Goods” means all Goods or Services supplied by the Supplier to the Customer at the Customer’s request from time to time (where the context so permits the terms ‘Goods’ or ‘Services’ shall be interchangeable for the other).

1.4   “Price” means the Price payable for the Goods as agreed between the Supplier and the Customer in accordance with clause 4 below.

 2.     Acceptance

2.1   The Customer is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Customer places an order for or accepts delivery of the Goods.

2.2   These terms and conditions may only be amended with the Supplier’s consent in writing and shall prevail to the extent of any inconsistency with any other document or agreement between the Customer and the Supplier.

 3.     Change in Control

3.1   The Customer shall give the Supplier not less than fourteen (14) days prior written notice of any proposed change of ownership of the Customer and/or any other change in the Customer’s details (including but not limited to, changes in the Customer’s name, address, contact phone or fax number/s, or business practice). The Customer shall be liable for any loss incurred by the Supplier as a result of the Customer’s failure to comply with this clause.

 4.     Price and Payment

4.1   At the Supplier’s sole discretion the Price shall be either:

(a)    as indicated on any invoice provided by the Supplier to the Customer; or

(b)    the Price as at the date of delivery of the Goods according to the Supplier’s current price list; or

(c)    the Supplier’s quoted price (subject to clause 4.2) which will be valid for the period stated in the quotation or otherwise for a period of thirty (30) days.

4.2   The Supplier reserves the right to change the Price if a variation to the Supplier’s quotation is requested. Any variation from the plan of scheduled works or specifications (including, but not limited to, any variation as a result of additional works required due to unforeseen circumstances such as poor weather conditions, limitations to accessing the site, availability of machinery, safety considerations, prerequisite work by any third party not being completed or as a result of any increase to the Supplier’s in the cost of materials and labour) will be charged for on the basis of the Supplier’s quotation and will be shown as variations on the invoice.  Payment for all variations must be made in full at their time of completion.

4.3   The Supplier may submit a detailed payment claim at intervals not less than one (1) month for work performed up to the end of each month.  The value of work so performed shall include the reasonable value of authorised variations, whether or not the value of such variations has been finally agreed between the parties, and the value of materials delivered to the site but not installed.  Progress payment shall be made within twenty (20) working days of each monthly payment claim.

4.4   Time for payment for the Goods being of the essence, the Price will be payable by the Customer on the date/s determined by the Supplier, which may be:

(a)    by way of instalments/progress payments in accordance with the Supplier’s payment schedule;

(b)    for certain approved Customers, due on the twentieth day of the month following the date of which the invoice is issued being posted or emailed to the Customer’s address or address for notices;

(c)    the date specified on any invoice or other form as being the date for payment; or

(d)    failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Customer by the Supplier.

4.5   Payment may be made by cash, cheque, bank cheque, electronic/on-line banking, Q Card, credit card (plus a surcharge of up to two percent (2%) of the Price), or by any other method as agreed to between the Customer and the Supplier.

4.6   Unless otherwise stated the Price does not include GST. In addition to the Price the Customer must pay to the Supplier an amount equal to any GST the Supplier must pay for any supply by the Supplier under this or any other agreement for the sale of the Goods. The Customer must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Customer pays the Price. In addition the Customer must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

 5.     Delivery

5.1   Subject to clause 5.2 it is the Supplier’s responsibility to ensure that the Services start as soon as it is reasonably possible.

5.2   The Services commencement date will be put back and the completion date extended by whatever time is reasonable in the event that the Supplier claims an extension of time (by giving the Customer written notice) where completion is delayed by an event beyond the Supplier’s control, including but not limited to any failure by the Customer to:

(a)    make a selection; or

(b)    have the site ready for the Services; or

(c)    notify the Supplier that the site is ready.

5.3   Delivery (“Delivery”) of the Goods is taken to occur at the time that the Supplier (or the Supplier’s nominated carrier) delivers the Goods to the Customer’s nominated address even if the Customer is not present at the address.

5.4   At the Supplier’s sole discretion the cost of delivery is either included in the Price, is in addition to the Price, or for the Customer’s account.

5.5   The Customer must take delivery by receipt or collection of the Goods whenever they are tendered for delivery. In the event that the Customer is unable to take delivery of the Goods as arranged then the Supplier shall be entitled to charge a reasonable fee for redelivery and/or storage.

5.6   The Customer shall take delivery of the Goods tendered notwithstanding that the quantity so delivered shall be either greater or lesser than the quantity purchased provided that:

(a)    such discrepancy in quantity shall not exceed five percent (5%); and

(b)    the Price shall be adjusted pro rata to the discrepancy.

5.7   The Supplier may deliver the Goods in separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.

5.8   Any time or date given by the Supplier to the Customer is an estimate only. The Customer must still accept delivery of the Goods even if late and the Supplier will not be liable for any loss or damage incurred by the Customer as a result of the delivery being late.

 6.     Risk

6.1   Risk of damage to or loss of the Goods passes to the Customer on Delivery and the Customer must insure the Goods on or before Delivery.

6.2   If any of the Goods are damaged or destroyed following delivery but prior to ownership passing to the Customer, the Supplier is entitled to receive all insurance proceeds payable for the Goods. The production of these terms and conditions by the Supplier is sufficient evidence of the Supplier’s rights to receive the insurance proceeds without the need for any person dealing with the Supplier to make further enquiries.

6.3   Where the Customer is to supply the Supplier with any design specifications (including, but not limited to CAD drawings) the Customer shall be responsible for providing accurate data. The Supplier shall not be liable whatsoever for any errors in the Goods that are caused by incorrect or inaccurate data being supplied by the Customer.

 7.     Electrical Risk

7.1   All work will be tested to ensure that it is electrically safe and is in accordance with the wiring rules and other standards applying to the electrical installation under the Electrical Safety Regulations.  All of the cabling work will comply with the Australian and New Zealand Wiring standards.

7.2   The Customer warrants that any structures to which the Goods are to be affixed are able to withstand the installation of the Goods and that any electrical connections (including, but not limited to, meter boxes, main switches, circuit breakers, and electrical cable) are of suitable capacity to handle the Goods once installed. If, for any reason (including the discovery of asbestos, defective or unsafe wiring, or dangerous access to roofing), the Supplier reasonably forms the opinion that the Customer’s premises is not safe for the installation of Goods to proceed then the Supplier shall be entitled to delay installation of the Goods (in accordance with the provisions of clause 5.2 above) until the Supplier is satisfied that it is safe for the installation to proceed.

7.3   Where the Customer has supplied materials for the Supplier to complete the Services, the Customer acknowledges that he accepts responsibility for the suitability of purpose, quality and any faults inherent in the materials. The Supplier shall not be responsible for any defects in the materials, any loss or damage to the Goods (or any part thereof), howsoever arising from the use of materials supplied by the Customer.

7.4   The Customer acknowledges that the Supplier is only responsible for parts that are replaced by the Supplier, and in the event that other parts/Goods, subsequently fail, the Customer agrees to indemnify the Supplier against any loss or damage to the Goods, or caused by the Goods, or any part thereof howsoever arising (including, but not limited to, loss of perishables, flooding and/or damage to clothing).

 8.     Air Conditioning Risk

8.1   Whilst the final location of the condensing unit is at the discretion of the Customer, a charge will apply as a variation as per clause 4.2, if the Customer requests the unit to not be located adjacent to the external wall, due to the underground piping required.

8.2   The final location of the wall, window or floor unit must be determined on site by the Customer.

8.3   The Supplier shall upon installation ensure that all installed Goods meet current industry standards applicable to noise levels, however the Supplier cannot guarantee that noise levels will remain constant post installation as the Goods may be impacted by many factors such as the weather, lack of maintenance, tampering etc.

8.4   In the event that any of the equipment needs to be relocated due to complaints from neighbours or local authorities, then the Customer shall be responsible for any and all costs involved.

8.5   The Customer acknowledges and agrees that it is their responsibility to insure any equipment partly or completely installed on site, against theft or damage.

8.6   In the event that the electrical wiring is required to be re-positioned at the request of any third party contracted by the Customer then the Customer agrees to notify the Supplier immediately upon any proposed changes.  The Customer agrees to indemnify the Supplier against any additional costs incurred with such a relocation of electrical wiring.  All such variances shall be invoiced in accordance with clause 4.2.

 9.     Dimensions, Plans and Specifications

9.1   All customary electrical industry tolerances shall apply to the dimensions and measurements of the Goods unless the Supplier and the Customer agree otherwise in writing.

9.2   The Supplier shall be entitled to rely on the accuracy of any plans, specifications and other information provided by the Customer

9.3   If the giving of an estimate or quotation for the supply of Goods involves the Supplier estimating measurements and quantities, it shall be the responsibility of the Customer to verify the accuracy of the Supplier’s estimated measurements and quantities, before the Customer places an order based on such estimate or accepts such quotation.

9.4   Should the Customer require any changes to the Supplier’s estimated measurements and quantities, the Customer shall request such changes in writing, in the case of an estimate before placing an order based on that estimate and in the case of a quotation before acceptance of that quotation.

 10.   Installation

10.1  Where the Supplier is to install Goods, installation will be carried out on the basis that the Customer will:

(a)    provide clear and free access to the worksite in order for the Supplier to complete the installation; and

(b)    provide all necessary services and amenities to enable the Supplier to carry out the installation; and

(c)    ensure that the worksite, including all foundations, are structurally sound and in a proper condition for the installation to proceed; and

(d)    provide all plant, materials, and services at such a time and in such a manner as to cause the Supplier no delay carrying out the installation.

 11.   Underground Locations

11.1  Prior to the Supplier commencing any work the Customer must advise the Supplier of the precise location of all underground services on the site and clearly mark the same. The underground mains & services the Customer must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.

11.2  Whilst the Supplier will take all care to avoid damage to any underground services the Customer agrees to indemnify the Supplier in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 11.1.

 12.   Title

12.1  The Supplier and the Customer agree that ownership of the Goods shall not pass until:

(a)    the Customer has paid the Supplier all amounts owing to the Supplier; and

(b)    the Customer has met all of its other obligations to the Supplier.

12.2  Receipt by the Supplier of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.

12.3  It is further agreed that:

(a)    until ownership of the Goods passes to the Customer in accordance with clause 12.1 that the Customer is only a bailee of the Goods and must return the Goods to the Supplier on request.

(b)    the Customer holds the benefit of the Customer’s insurance of the Goods on trust for the Supplier and must pay to the Supplier the proceeds of any insurance in the event of the Goods being lost, damaged or destroyed.  

(c)    the Customer must not sell, dispose, or otherwise part with possession of the Goods other than in the ordinary course of business and for market value. If the Customer sells, disposes or parts with possession of the Goods then the Customer must hold the proceeds of any such act on trust for the Supplier and must pay or deliver the proceeds to the Supplier on demand.

(d)    the Customer should not convert or process the Goods or intermix them with other goods but if the Customer does so then the Customer holds the resulting product on trust for the benefit of the Supplier and must sell, dispose of or return the resulting product to the Supplier as it so directs.

(e)    the Customer irrevocably authorises the Supplier to enter any premises where the Supplier believes the Goods are kept and recover possession of the Goods.

(f)     the Supplier may recover possession of any Goods in transit whether or not delivery has occurred.

(g)    the Customer shall not charge or grant an encumbrance over the Goods nor grant nor otherwise give away any interest in the Goods while they remain the property of the Supplier.

(h)    the Supplier may commence proceedings to recover the Price of the Goods sold notwithstanding that ownership of the Goods has not passed to the Customer.

 13.   Personal Property Securities Act 1999 (“PPSA”)

13.1  Upon assenting to these terms and conditions in writing the Customer acknowledges and agrees that:

(a)    these terms and conditions constitute a security agreement for the purposes of the PPSA; and

(b)    a security interest is taken in all Goods previously supplied by the Supplier to the Customer (if any) and all Goods that will be supplied in the future by the Supplier to the Customer.

13.2  The Customer undertakes to:

(a)    sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Supplier may reasonably require to register a financing statement or financing change statement on the Personal Property Securities Register;

(b)    indemnify, and upon demand reimburse, the Supplier for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register or releasing any Goods charged thereby;

(c)    not register a financing change statement or a change demand without the prior written consent of the Supplier; and

(d)    immediately advise the Supplier of any material change in its business practices of selling the Goods which would result in a change in the nature of proceeds derived from such sales.

13.3  The Supplier and the Customer agree that nothing in sections 114(1)(a), 133 and 134 of the PPSA shall apply to these terms and conditions.

13.4  The Customer waives its rights as a debtor under sections 116, 120(2), 121, 125, 126, 127, 129, 131 and 132 of the PPSA.

13.5  Unless otherwise agreed to in writing by the Supplier, the Customer waives its right to receive a verification statement in accordance with section 148 of the PPSA.

13.6  The Customer shall unconditionally ratify any actions taken by the Supplier under clauses 13.1 to 13.5.

 14.   Security and Charge

14.1  In consideration of the Supplier agreeing to supply the Goods, the Customer charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Customer either now or in the future, to secure the performance by the Customer of its obligations under these terms and conditions (including, but not limited to, the payment of any money).

14.2  The Customer indemnifies the Supplier from and against all the Supplier’s costs and disbursements including legal costs on a solicitor and own Customer basis incurred in exercising the Supplier’s rights under this clause.

14.3  The Customer irrevocably appoints the Supplier and each director of the Supplier as the Customer’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 14 including, but not limited to, signing any document on the Customer’s behalf.

 15.   Customer’s Disclaimer

15.1  The Customer hereby disclaims any right to rescind, or cancel any contract with the Supplier or to sue for damages or to claim restitution arising out of any inadvertent misrepresentation made to the Customer by the Supplier and the Customer acknowledges that the Goods are bought relying solely upon the Customer’s skill and judgment.

 16.   Defects

16.1  The Customer shall inspect the Goods on delivery and shall within fourteen (14) days of delivery (time being of the essence) notify the Supplier of any alleged defect, shortage in quantity, damage or failure to comply with the description or quote.  The Customer shall afford the Supplier an opportunity to inspect the Goods within a reasonable time following delivery if the Customer believes the Goods are defective in any way. If the Customer shall fail to comply with these provisions the Goods shall be presumed to be free from any defect or damage. For defective Goods, which the Supplier has agreed in writing that the Customer is entitled to reject, the Supplier’s liability is limited to either (at the Supplier’s discretion) replacing the Goods or repairing the Goods.

16.2  Goods will not be accepted for return other than in accordance with 16.1 above.

 17.   Warranty

17.1  Subject to the conditions of warranty set out in clause 17.2 the Supplier warrants that if any defect in any workmanship of the Supplier becomes apparent and is reported to the Supplier within twelve (12) months of the date of delivery (time being of the essence) then the Supplier will either (at the Supplier’s sole discretion) replace or remedy the workmanship.

17.2  The conditions applicable to the warranty given by clause 17.1 are:

(a)    the warranty shall not cover any defect or damage which may be caused or partly caused by or arise through:

(i)     failure on the part of the Customer to properly maintain any Goods; or

(ii)    failure on the part of the Customer to follow any instructions or guidelines provided by the Supplier; or

(iii)   any use of any Goods otherwise than for any application specified on a quote or order form; or

(iv)    the continued use of any Goods after any defect becomes apparent or would have become apparent to a reasonably prudent operator or user; or

(v)    fair wear and tear, any accident or act of God.

(b)    the warranty shall cease and the Supplier shall thereafter in no circumstances be liable under the terms of the warranty if the workmanship is repaired, altered or overhauled without the Supplier’s consent.

(c)    in respect of all claims the Supplier shall not be liable to compensate the Customer for any delay in either replacing or remedying the workmanship or in properly assessing the Customer’s claim.

17.3  For Goods not manufactured by the Supplier, the warranty shall be the current warranty provided by the manufacturer of the Goods. The Supplier shall not be bound by nor be responsible for any term, condition, representation or warranty other than that which is given by the manufacturer of the Goods.

 18.   Consumer Guarantees Act 1993

18.1  If the Customer is acquiring Goods for the purposes of a trade or business, the Customer acknowledges that the provisions of the Consumer Guarantees Act 1993 do not apply to the supply of Goods by the Supplier to the Customer.

 19.   Intellectual Property

19.1  Where the Supplier has designed, drawn or developed Goods for the Customer, then the copyright in any designs and drawings and documents shall remain the property of the Supplier.

19.2  The Customer warrants that all designs, specifications or instructions given to the Supplier will not cause the Supplier to infringe any patent, registered design or trademark in the execution of the Customer’s order and the Customer agrees to indemnify the Supplier against any action taken by a third party against the Supplier in respect of any such infringement.

19.3  The Customer agrees that the Supplier may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, digital or photographic images, drawings or Goods which the Supplier has created for the Customer.

 20.   Default and Consequences of Default

20.1  Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Supplier’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.

20.2  If the Customer owes the Supplier any money the Customer shall indemnify the Supplier from and against all costs and disbursements incurred by the Supplier in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own Customer basis, the Supplier’s collection agency costs, and bank dishonour fees).

20.3  If any account remains overdue after thirty (30) days then an amount of the greater of $20.00 or 10.00% of the amount overdue (up to a maximum of $200) shall be levied for administration fees which sum shall become immediately due and payable.

20.4  Without prejudice to any other remedies the Supplier may have, if at any time the Customer is in breach of any obligation (including those relating to payment) under these terms and conditions the Supplier may suspend or terminate the supply of Goods to the Customer. The Supplier will not be liable to the Customer for any loss or damage the Customer suffers because the Supplier has exercised its rights under this clause.

20.5  Without prejudice to the Supplier’s other remedies at law the Supplier shall be entitled to cancel all or any part of any order of the Customer which remains unfulfilled and all amounts owing to the Supplier shall, whether or not due for payment, become immediately payable if:

(a)    any money payable to the Supplier becomes overdue, or in the Supplier’s opinion the Customer will be unable to make a payment when it falls due;

(b)    the Customer becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or

(c)    a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Customer or any asset of the Customer.

 21.   Cancellation

21.1  The Supplier may cancel any contract to which these terms and conditions apply or cancel delivery of Goods at any time before the Goods are delivered by giving written notice to the Customer. On giving such notice the Supplier shall repay to the Customer any money paid by the Customer for the Goods. The Supplier shall not be liable for any loss or damage whatsoever arising from such cancellation.

21.2  In the event that the Customer cancels delivery of Goods the Customer shall be liable for any and all loss incurred (whether direct or indirect) by the Supplier as a direct result of the cancellation (including, but not limited to, any loss of profits).

21.3  Cancellation of orders for Goods made to the Customer’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

22.   Privacy Act 1993

22.1  The Customer authorises the Supplier or the Supplier’s agent to:

(a)    access, collect, retain and use any information about the Customer;

(i)     (including any overdue fines balance information held by the Ministry of Justice) for the purpose of assessing the Customer’s creditworthiness; or

(ii)    for the purpose of marketing products and services to the Customer.

(b)    disclose information about the Customer, whether collected by the Supplier from the Customer directly or obtained by the Supplier from any other source, to any other credit provider or any credit reporting agency for the purposes of providing or obtaining a credit reference, debt collection or notifying a default by the Customer.

22.2  Where the Customer is an individual the authorities under clause 22.1 are authorities or consents for the purposes of the Privacy Act 1993.

22.3  The Customer shall have the right to request the Supplier for a copy of the information about the Customer retained by the Supplier and the right to request the Supplier to correct any incorrect information about the Customer held by the Supplier.

23.   Unpaid Seller’s Rights

23.1  Where the Customer has left any item with the Supplier for repair, modification, exchange or for the Supplier to perform any other service in relation to the item and the Supplier has not received or been tendered the whole of any moneys owing to it by the Customer, the Supplier shall have, until all moneys owing to the Supplier are paid:

(a)    a lien on the item; and

(b)    the right to retain or sell the item, such sale to be undertaken in accordance with any legislation applicable to the sale or disposal of uncollected goods.

23.2  The lien of the Supplier shall continue despite the commencement of proceedings, or judgment for any moneys owing to the Supplier having been obtained against the Customer.

 24.   Dispute Resolution

24.1  All disputes and differences between the Customer and the Supplier touching and concerning this agreement shall be referred to arbitration under a single arbitrator agreed upon by both parties, or failing agreement, by two arbitrators (one to be appointed by each party) and their umpire (appointed by them prior to arbitration), such arbitration to be carried out in accordance with provisions of the Arbitration Act 1996.

 25.   Compliance with Laws

25.1  The Customer and the Supplier shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the works.

25.2  The Customer shall obtain (at the expense of the Customer) all licenses and approvals that may be required for the works.

25.3  The Customer agrees that the site will comply with any occupational health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.

 26.   Construction Contracts Act 2002

26.1  The Customer hereby expressly acknowledges that:

(a)    the Supplier has the right to suspend work within five (5) working days of written notice of its intent to do so if a payment claim is served on the Customer, and:

(i)     the payment is not paid in full by the due date for payment and no payment schedule has been given by the Customer; or

(ii)    a scheduled amount stated in a payment schedule issued by the Customer in relation to the payment claim is not paid in full by the due date for its payment; or

(iii)   the Customer has not complied with an adjudicator’s notice that the Customer must pay an amount to the Supplier by a particular date; and

(iv)    the Supplier has given written notice to the Customer of its intention to suspend the carrying out of construction work under the construction contract.

(b)    if the Supplier suspends work, it:

(i)     is not in breach of contract; and

(ii)    is not liable for any loss or damage whatsoever suffered, or alleged to be suffered, by the Customer or by any person claiming through the Customer; and

(iii)   is entitled to an extension of time to complete the contract; and

(iv)    keeps its rights under the contract including the right to terminate the contract; and may at any time lift the suspension, even if the amount has not been paid or an adjudicator’s determination has not been complied with.

(c)    if the Supplier exercises the right to suspend work, the exercise of that right does not:

(i)     affect any rights that would otherwise have been available to the Supplier under the Contractual Remedies Act 1979; or

(ii)    enable the Customer to exercise any rights that may otherwise have been available to the Customer under that Act as a direct consequence of the Supplier suspending work under this provision.

 27.   General

27.1  The failure by the Supplier to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect the Supplier’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.

27.2  These terms and conditions and any contract to which they apply shall be governed by the laws of New Zealand and are subject to the jurisdiction of the courts of New Zealand. 

27.3  The Supplier shall be under no liability whatsoever to the Customer for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Customer arising out of a breach by the Supplier of these terms and conditions (alternatively the Supplier’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Goods).

27.4  The Customer shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Customer by the Supplier nor to withhold payment of any invoice because part of that invoice is in dispute.

27.5  The Supplier may license or sub-contract all or any part of its rights and obligations without the Customer’s consent.

27.6  The Customer agrees that the Supplier may amend these terms and conditions at any time. If the Supplier makes a change to these terms and conditions, then that change will take effect from the date on which the Supplier notifies the Customer of such change. The Customer will be taken to have accepted such changes if the Customer makes a further request for the Supplier to provide Goods to the Customer.

27.7  Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.

27.8  The Customer warrants that it has the power to enter into this agreement and has obtained all necessary authorisations to allow it to do so, it is not insolvent and that this agreement creates binding and valid legal obligations on it.

Total Electrical Solutions

Terms and Conditions